Anaheim California Expert Witness Engineer Directory

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Insured's Collapse Claim Survives Summary Judgment

October 28, 2024 — Tred R. Eyerly - Insurance Law Hawaii
The insurer's motion for summary judgment seeking to dispose of the insured's claim for collapse was denied. Life Skills, Inc. v. Harleysville Ins. Co., 2024 U.S. Dist. LEXIS 143658 (D. Mass. Aug. 13, 2024). Life Skills was a non-profit social service agency providing residential and day habilitation services to adults with autism and intellectual and developmental disabilities. The head office was covered by a policy issued by Harleysville with building coverage limits of $3,038,300. Damage occurred in a ceramics classroom located in the basement of the building. The floor sank between eight to twelve inches in the northeast corner. The ceramics classroom contained two large kilns weighing approximately 200 pounds. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Colorado Court of Appeals’ Ruling Highlights Dangers of Excessive Public Works Claims

August 26, 2024 — David M. McLain – Colorado Construction Litigation
In the case of Ralph L. Wadsworth Construction Company, LLC v. Regional Rail Partners (2024 COA 78), the Colorado Court of Appeals reviewed a complex contract dispute related to the design and construction of a transit rail line. The project, commissioned by the Regional Transportation District (“RTD”), involved a collaboration between Regional Rail Partners and Ralph L. Wadsworth Construction Company (“Wadsworth”) to build the North Metro Rail Line between Denver Union Station and Thornton. Key Facts:

Contracts and Payments: Regional Rail Partners contracted with Wadsworth to perform specific construction tasks with a total contract value of $60,210,783. By the time of the trial, Regional Rail had paid almost $58 million of this amount.
Disputes and Delays: The project faced numerous delays and disputes, leading to Wadsworth claiming significant financial damages attributed to these disruptions. In April 2018, Wadsworth’s expert estimated that Regional Rail owed them $12,408,496.60.

Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell, LLC
Mr. McLain may be contacted at mclain@hhmrlaw.com

“Bound by the Bond”

September 02, 2024 — Daniel Lund III - Lexology
A New York trial court granted judgment in favor of a performance bond surety on a construction project, based upon the failure of the claiming party to abide by the terms of the bond. The “AIA Document A312” bond form – described by the court (quoting surety law authority) to be “one of the clearest, most definitive, and widely used type of traditional common law ‘performance bonds’ in private construction” – contains various procedures which must be honored as a “condition precedent to an action to recover” on the bond/against the surety. One of those prerequisites is a “declaration of default” concerning the contractor principal (here, a subcontractor). The case involved the construction of an 85-story skyscraper in midtown Manhattan, and the performance of the subcontract for the building’s superstructure. The bonded contract was at a value of approximately $25,000,000 and obligated the sub to provide a performance bond “in a form similar to the [A312 bond],” and which was otherwise satisfactory to the obligee/construction manager. Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Newport Beach Attorneys John Toohey and Nick Rodriguez Receive Full Defense Verdict

July 31, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara is pleased to report that Partner John Toohey and Senior Associate Nicholas Rodriguez received a complete defense verdict after a 5-week jury trial in Orange County Superior Court. The case involved a multimillion-dollar home in Orange County. Plaintiff had originally suffered a water loss throughout areas of the home. Our client, an Orange County restoration and construction company, was hired to provide on-going estimates and perform demolition. Plaintiff claimed that, in the course of the demolition process, asbestos containing material was disturbed and spread resulting in contamination throughout home. Plaintiff claimed contractor negligence and breach of contract against our client. Plaintiff sought millions against our client in general and special damages for whole home restoration and other related general damages. The jury found in complete favor of our client on all allegations and awarded zero dollars to the opposing party. Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

Nine ACS Lawyers Recognized as Super Lawyers – Two Recognized as Rising Stars

August 26, 2024 — Ahlers Cressman & Sleight PLLC
Going outside the norm of our blogs, which usually discuss construction related issues, Ahlers, Cressman, & Sleight is pleased to announce that nine members of our firm have been selected to the 2024 Washington Super Lawyers list. Each year, a rigorous process that involves a nomination by peers and a third-party verification of honors, awards, verdicts, settlements, and other criteria relating to their work as an attorney, aims to select no more than five percent of the lawyers in Washington state from no more than seventy practice areas for this distinction. As mentioned, the first step in the process is to be evaluated on their work as an attorney, next candidates are evaluated by their peers and given ratings based on the information known about their work. Finally, candidates are grouped into four firm-size categories and final selections are made. The grouping process is done so that candidates are compared fairly to their peers by firm size, eliminating the potential unfairness that comes with comparing large and small firm outcomes and attorney practices. The Rising Star list involves an even narrower criteria than the Super Lawyers list. The initial process is the same, however, candidates for the Rising Stars list must be under the age of forty or have less than ten years of experience. For this category less the two and a half percent of lawyers in Washington are selected, making this quite a feat for those who have accomplished the honor. Read the full story...
Reprinted courtesy of Ahlers Cressman & Sleight PLLC

“A No-Lose Proposition?”

October 07, 2024 — Daniel Lund III - Lexology
A Miller Act payment bond surety and its principal general contractor both sued in federal court in New Orleans by a project subcontractor sought to compel arbitration the claims against both contractor and surety based on an indisputably enforceable arbitration clause in the subcontract. This was urged to avoid separate actions against the contractor (arbitration) and its surety (litigation), even though the surety was not a party to the subcontract and, therefore, not a party to the arbitration clause. In the face of the lack of an express agreement to arbitrate, the contractor and contractor argued that “no federal statute or policy prohibits all of Plaintiff’s claims from proceeding to arbitration….” Additionally, those parties urged that the surety should be allowed to affirmatively compel arbitration because the surety “would otherwise have the ability to assert the right to compel arbitration as a defense….” The New Orleans federal district court was unpersuaded:

“[D]istrict courts within this circuit have recognized that ‘Miller Act claims by a subcontractor for unpaid labor and materials are separate and distinct from those for general breach of contract… [and] arbitration and Miller Act suits, are not, per se, inconsistent with one another.’…[A]bsent express contractual intent to subject Miller Act claims to arbitration, the court [will] not force the parties to arbitrate claims against nonparties to the contract at issue…. [C]laims against a surety, which was a non-signatory to the contract, would not be subject to arbitration without any contractual basis to do so.”

Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Corrective Action Protest Grounds for GSA Schedule Federal Construction Contractors

September 09, 2024 — Marissa L. Downs - The Dispute Resolver
A contract awarded, protested, terminated, appealed, then reinstated. It’s no secret that federal construction procurements are plagued with uncertainty. From delays, constructive suspensions, compromised supply chains, the litigation-laden critical path method, and the mandate for all construction materials used in federally funded projects for infrastructure to be produced in the United States under the Build America, Buy America Act (BABAA) (to name just a few traditional and emerging favorites), just one of these issues could fill the rest of anyone’s month with substantive research. To add one more, which is entirely unique to bid protests, federal contractors–including construction contractors–listed in a General Service Administration (GSA) Schedule may have new grounds to have a contract award reinstated that was terminated by a federal agency pending a GAO decision. GAO Protest An initial GAO protest filed by Deloitte & Touche LLP (Deloitte) argued that the National Geo-Spatial Intelligence Agency (Agency) wrongfully made an award to Kearney & Company, P.C. (Kearney) when the Agency: (1) improperly evaluated quotes; and (2) failed to conduct a proper best-value tradeoff analysis. At issue was a competed task order with Kearney under a GSA FSS multiple-award contract. Before the GAO issued an opinion, however, it held an unrecorded predictive-outcome conference with Deloitte and Kearney where the only mutual consensus was the likely ineligibility of all offerors for the relevant award. The Agency subsequently elected to take corrective action, terminating Kearney’s contract award for convenience, amending the solicitation to avoid issues (including undisputed issues) addressed in the GAO protest. After the Agency adopted their corrective action, the GAO protest was dismissed as academic and moot. Read the full story...
Reprinted courtesy of Marissa L. Downs, Laurie & Brennan, LLP
Ms. Downs may be contacted at mdowns@lauriebrennan.com

ANAHEIM CALIFORNIA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES