Anaheim California Expert Witness Engineer Directory

Nine ACS Lawyers Recognized by Best Lawyers®

September 02, 2024 — Ahlers Cressman & Sleight PLLC
Departing from our blog’s typical coverage of construction related issues, Ahlers Cressman & Sleight PLLC is proud to announce that nine members of our firm have been recognized by Best Lawyers® in 2025 in America. Recognition by Best Lawyers® is based entirely on peer review and is designed to reflect the consensus opinion of leading lawyers about the professional abilities of their colleagues. Lawyers can be nominated by clients and other lawyers. After nomination, ballots are generated and distributed to lawyers. Voters are asked how likely they would be to refer a case to the nominee and to give a rating and additional comments. Ballots are designed based on the voter’s practice area and geographic region. After feedback is analyzed, Best Lawyers® research staff ensures nominees are in good standing with the ethics committee of their state bar and selects lawyers for recognition. Read the full story...
Reprinted courtesy of Ahlers Cressman & Sleight PLLC

Recovering Time and Costs from Hurricane Helene: Force Majeure Solutions for Contractors

November 18, 2024 — Matthew DeVries - Best Practices Construction Law
When Hurricane Helene struck North Carolina, it caused severe disruptions to construction projects across the state. Baxter International’s North Cove facility in Marion, N.C., was completely shut down after floodwaters damaged the site and bridges leading to it. Elsewhere, landslides and floods wiped out large sections of Interstate 40, making transportation of materials and equipment nearly impossible. Many contractors in western North Carolina found their projects halted, and their schedules thrown off by this force majeure event. In situations like these, contractors and subcontractor need a plan to mitigate the impact of such natural disasters on their projects. Here are five practical tips to help you secure time extensions and/or compensation for delays: 1. Include a Robust Force Majeure Clause in Your Contract When disaster strikes, your contract is your first line of defense. A well-drafted force majeure clause can make the difference between bearing the costs yourself and getting an extension or compensation. The clause should clearly list specific events such as hurricanes, floods, and road closures as qualifying force majeure events. Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

Nuclear Fusion Pushes to Reach Commercial Power Plant Stage

August 05, 2024 — Mary B. Powers, Debra K. Rubin, Peter Reina & David Godkin - Engineering News-Record
The quest to develop nuclear fusion—the process that energizes the sun and other stars—as an earth-based power source dates back more than a century when Albert Einstein and other scientists theorized how enormous amounts of energy could be produced when atoms fuse. That research was partly diverted for wartime weapons priorities but later targeted to develop fusion for commercial-scale energy—what sector proponents have called the “holy grail” for decades since. Reprinted courtesy of Mary B. Powers, Engineering News-Record, Debra K. Rubin, Engineering News-Record, Peter Reina, Engineering News-Record and David Godkin, Engineering News-Record Ms. Rubin may be contacted at rubind@enr.com Mr. Reina may be contacted at reina@btinternet.com Read the full story...

Resilience: Transforming the Energy Sector – Navigating Land Issues in Solar and Storage Projects | Episode 3 (11.14.24)

December 17, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In the latest episode of the Resilience podcast, colleague Shellka Arora-Cox and Laura Pagliarulo, CEO and founder of SolaREIT, get down to the nitty-gritty in a discussion of the interplay of solar power capacity, generation and land use. (Editor’s note: The following transcript has been edited for clarity.) Welcome to Resilience, the vodcast where we talk about the most pressing challenges and the biggest opportunities in the energy sector. I’m your host, Shellka Arora-Cox, a partner at Pillsbury Winthrop Shaw Pittman. I’m thrilled to have Laura Pagliarulo, the CEO and founder of SolaREIT, with me today. Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

'You're Talking About Lives': The New Nissan Stadium

August 26, 2024 — Grace Austin - Construction Executive
The new Tennessee Titans sports complex rising up on the banks of the Cumberland River in Nashville is a big project no matter how you look at it. Nissan Stadium will have 60,000 seats, cover 1.85 million square feet and cost an estimated $2.1 billion. Four contractors are involved, operating under a joint venture called the Tennessee Builders Alliance: Turner Construction Co., AECOM Hunt, Polk & Associates Construction and I.C.F. Builders & Consultants. And nearly 20,000 workers will play a role over the project’s three-year timeline. The sheer size and scope of the job led Tyler White, TBA’s environmental health and safety director, to think that the project needed to approach safety on a similar scale. The result is a first-of-its-kind public-private partnership between the Tennessee Occupational Safety and Health Administration and TBA. “I thought it would be a good idea,” White says. “I know they’re stretched thin, but [we’re] very appreciate of advocating and allocating their resources.” Reprinted courtesy of Grace Austin, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

The Impact of Nuclear Verdicts on Construction Businesses

October 28, 2024 — Craig Tappel - Construction Executive
A rush to build at a time when the U.S. housing supply continues to fall short may come with a cost to the construction industry. Particularly in hot markets—Sun Belt states and the Mountain West—the drive to finish fast, if not big, can lead to construction and design-defect litigation. Last fall, for example, $22 million in damages were awarded to 220 unhappy homeowners in a South Carolina subdivision northwest of Charleston, four years after their claim for defective work was filed against a major U.S. homebuilder and its subcontractors. Defective work is one of three areas where the construction industry is particularly vulnerable as class-action litigation and thermonuclear verdicts surge. Another is the risk of loss of life or permanent disability on a site, and not solely involving workers: Over $860 million was awarded in 2023 to the family of a woman who was killed in a 2019 crane collapse at a Dallas construction site. Reprinted courtesy of Craig Tappel, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

Hawaii Supreme Court Finds Climate Change Lawsuit Barred by “Pollution Exclusion”

November 05, 2024 — Jason Taylor - Traub Lieberman Insurance Law Blog
On October 7, 2024, the Hawaii Supreme Court answered the question of whether an “accident” includes an insured’s reckless conduct in emitting harmful greenhouse gases (“GHGs”) and whether such emissions are “pollutants” as defined in a general liability policy’s pollution exclusion. In Aloha Petro., Ltd. v. National Union Fire Insurance Co. of Pitt., PA, No., 2024 Haw. LEXIS 179 (Oct. 7, 2024), the Hawaii Supreme Court answered in the affirmative as to both certified questions from the United States District Court for the District of Hawaii, holding that an insured’s reckless conduct can be an “accident” and that GHGs are “pollutants” under the policies’ pollution exclusions. In the underlying case, the County of Honolulu and the County of Maui (the “Counties”) sued Aloha Petroleum, Ltd. (“Aloha”) and several other fossil fuel companies for climate change-related harms. Namely, the Counties alleged that the fossil fuel industry knew that its products would cause catastrophic climate change, and rather than mitigating their emissions, defendants concealed such knowledge, promoted climate science denial, and increased their production of fossil fuels. Aloha was allegedly on notice that its products caused harmful climate change through its former parent company, Phillips 66, and its current parent company, Sunoco. Given this knowledge, the District Court determined that the Counties allegations constituted reckless conduct by Aloha. Read the full story...
Reprinted courtesy of Jason Taylor, Traub Lieberman
Mr. Taylor may be contacted at jtaylor@tlsslaw.com

ANAHEIM CALIFORNIA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES