Anaheim California Expert Witness Engineer Directory

There Are Consequences to Executed Documents Such as the Accord and Satisfaction Defense

October 01, 2024 — David Adelstein - Florida Construction Legal Updates
A federal government contractor in Jackson Construction Co., Inc. v. U.S., 62 Fed.Cl. 84 (Fed.Cl. 2024) sought delay damages against the government. It lost. The reason for the loss is a crucial reminder that documents parties sign ALWAYS matter. ALWAYS!! In Jackson Construction Co., the contractor’s delay claim was premised on relocating a waterline. The contractor, however, received additional money for relocating the waterline, but no additional time, and this was memorialized in a modification to the contract (i.e., a change order). In executing the modification for the additional work, the contractor did NOT reserve rights for time or money. Indeed, the modification reflected that the monetary adjustment constitutes full compensation for the additional work including delay, namely:

The contract period of performance remains the same. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the contractor and his subcontractors and suppliers for all costs and markup directly or indirectly, including extended overhead, attributable to the change order, for all delays related thereto, and for performance of the change within the time frame stated.

Jackson Construction Co., supra, at 90.

Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

EEOC Focuses on Eliminating Harassment, Recruitment and Hiring Barriers in the Construction Industry

September 09, 2024 — Aaron C. Schlesinger & Stephen E. Irving - Peckar & Abramson, P.C.
The Equal Employment Opportunity Commission (EEOC), whose mission is to enforce the nation’s anti-discrimination laws, released new guidelines on June 18, 2024, entitled Promising Practices for Preventing Harassment in the Construction Industry. The guidelines are in support of its Strategic Enforcement Plan for the fiscal years 2024-2028 for combatting systemic harassment and eliminating barriers in recruitment and hiring in the construction industry. With these guidelines, the EEOC has identified harassment as an ongoing issue in the construction industry, and that immediate attention and resolution is required. The EEOC specifically recommends that the following five core principles that it has found effective in preventing and addressing harassment be implemented by construction industry employers:

Committed and engaged leadership;
Consistent and demonstrated accountability;
Strong and comprehensive harassment policies;
Trusted and accessible complaint procedures; and
Regular, interactive training tailored to the audience and the organization.

Reprinted courtesy of Aaron C. Schlesinger, Peckar & Abramson, P.C. and Stephen E. Irving, Peckar & Abramson, P.C. Mr. Schlesinger may be contacted at aschlesinger@pecklaw.com Mr. Irving may be contacted at sirving@pecklaw.com Read the full story...

Hawaii Supreme Court Reaffirms an "Accident" Includes Reckless Conduct, Finds Green House Gases are Pollutants

November 18, 2024 — Tred R. Eyerly - Insurance Law Hawaii
Answering certified questions from the federal district court, the Hawaii Supreme Court reaffirmed its prior holding that reckless conduct is an "occurrence' or accident. The court further held that green house gas (GHG) emissions were pollutants under liability policies. Aloha Petroleum, Ltd. v. National Union Fire Ins. Co. of Pittsburg, PA., et al., 2024 Haw. LEXIS 179 (Haw. Oct. 7, 2024). [Disclosure - our office was co-counsel on an amicus brief in this case filed on behalf of the United Policyholders]. The City and County of Honolulu and the County of Maui sued several fossil fuel companies, including Aloha Petroleum, Ltd., for climate change-related harms. The suits alleged that the fossil fuel industry knew beginning in the 1960s that its products would cause catastrophic climate change. Rather than mitigate their emissions, defendants concealed their knowledge of climate change, promoted climate science denial, and increased their production of fossil fuels. Defendants' actions, the complaints alleged, increased carbon emissions, which caused significant damage to the counties. Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

The Privette Doctrine and Its Exceptions: Court of Appeal Grapples With the Easy and Not So Easy

November 18, 2024 — Garret Murai - California Construction Law Blog
In CBRE v. Superior Court, 102 Cal.App.5th 639 (2024), the 4th District Court of Appeal grappled with a thorny and not-so-thorny issue involving injured parties under the Privette doctrine. The less thorny issue was whether application of the Privette doctrine depends on whether a written contract exists between the parties. Spoiler: It does not. The thorny issue was whether the Hooker exception to the Privette doctrine – which applies when a landowner exercises control over a project – should apply where a landowner directs a contractor to perform work that is at odds with legal requirements. The CBRE Case Property Reserve, Inc. owns an office building managed by CBRE in San Diego, California. On April 9, 2019, PRI entered into a lease agreement with a new tenant for a suite in the building. The lease required that PRI perform certain tenant improvements. Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Construction Litigation Roundup: “D’Oh!”

August 12, 2024 — Daniel Lund III - Lexology
The U.S. DOL found itself on June 24 on the wrong end of a preliminary injunction concerning recent changes to the Davis-Bacon Act. The lawsuit, initiated in Texas federal court by the Associated General Contractors of America and other concerned citizens, sought a preliminary injunction barring implementation and enforcement of “specified portions of § 5.2 and § 5.5(e) of the DOL’s ‘Updating the Davis-Bacon and Related Acts Regulations’” – the “Final Rule,” published August 23, 2023. After determining the appropriateness of the “standing” of the plaintiffs based upon the plaintiffs being “adversely affected” by the Final Rule, the federal court preliminarily enjoined enforcement of the Final Rule. In noting its disagreement with the Final Rule, the court stated:

“… the Final Rule amends the DBA [the Davis-Bacon Act] by imposing a stealth selfimplementing DBA requirement in the contract by an operation-of-law provision that contradicts the express statutory language of the Act [the court bristling at the idea that contracts might exclude with impunity the otherwise mandated DBA clauses]. Further, the Final Rule amends the Act to extend the DBA to apply to workers who are not mechanics and laborers, and to extend the scope of the work covered by DBA to include work is not performed ‘directly on the site of the work.’

Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Utilities’ Extreme Plan to Stop Wildfires: Shut Off the Power

October 28, 2024 — Mark Chediak - Bloomberg
A growing number of utilities are resorting to an extreme measure to prevent their equipment from sparking catastrophic wildfires: turning off the power. Electric companies serving about 24 million homes and businesses across the fire-prone US West now have plans to preemptively cut electricity during dangerous fire conditions, according to an analysis of data compiled by researchers at Stanford University. The proactive blackouts, however, run counter to the power companies’ main mission — which is to keep the lights on. And that’s angering customers and officials. Lawsuits — and the billions of dollars of damage claims that come with them — are an increasing concern among utilities, said Michael Wara, who leads the Climate and Energy Policy Program at Stanford University. Read the full story...
Reprinted courtesy of Mark Chediak, Bloomberg

Deterioration of Bridge Infrastructure Is Increasing Insurance Needs

December 03, 2024 — Grace Calengor - Construction Executive
As the world is taken by storm—literally, with increasing hurricanes, tornadoes, wildfires and more—insuring construction projects and infrastructure is becoming more complicated yet more necessary. Sean Pender, senior vice president of construction and development at CAC Specialty, is a leading specialty insurance broker and advisor. As major-storm season for the Northern hemisphere rounds out, he speaks with Construction Executive about the potential risk and insurance implications to the process of ensuring proper repairs, replacements and other forms of maintenance to one of the country’s most pivotal pieces of infrastructure: bridges. What does insurance coverage look like for building bridges in various environments throughout the country? Insurance is essential to protect the entity that owns the bridge during construction. Bridges under construction are at the highest risk of collapse because they are not yet fully stabilized and are exposed to severe weather and natural disasters, which could cause significant damage to the structure or injury to workers and civilians. Therefore, comprehensive liability insurance programs—typically with coverage limits of $50 to $100 million or higher—are crucial, especially with activities on or over waterways. Reprinted courtesy of Grace Calengor, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the full story...

FEMA Offers Recovery Tips for California Wildfire Survivors

January 14, 2025 — FEMA
WASHINGTON -- While fire suppression activities are still ongoing in parts of Southern California, affected individuals and families are taking steps toward recovery. FEMA is helping people jumpstart their recovery. You may be eligible for FEMA assistance, even if you have insurance. More than $5.3 million so far are in the hands of survivors to help pay for emergency supplies like food, water and baby formula as well as to replace personal property and pay for a temporary place to stay. Below are tips to help Californians recover from the historic wildfires. If your primary home was affected by the fires, FEMA may be able to help you cover certain costs – like paying for essential items, finding a place to stay, replacing personal property or making basic repairs to your home. However, FEMA assistance is designed to help you if you do not have insurance or if your insurance policies don't cover basic needs. If you have insurance, you should file a claim as soon as possible and be ready to provide your coverage information when applying to FEMA. There are several ways to apply for FEMA assistance:

Online at DisasterAssistance.gov and in Spanish language at DisasterAssistance.gov/es.
Calling the FEMA Helpline at 1-800-621-3362 for assistance in multiple languages.
On the FEMA App for mobile devices.

To view an accessible video about how to apply visit: FEMA Accessible: Registering for Individual Assistance or en Español.

ANAHEIM CALIFORNIA CONSTRUCTION EXPERT WITNESS DIRECTORY AND CAPABILITIES