Grand Ridge Florida Expert Witness Engineer Directory

Render Unto Caesar: Considerations for Returning Withheld Sums

January 18, 2021 — William E. Underwood Partner, Jones Walker LLP - ConsensusDocs
Withholding sums during a dispute can be an effective and perfectly legitimate means to protect against the harms caused by another party’s breach. However, withholding too much money during a dispute can turn a position of strength into one of weakness. “Why should I fund the other side’s litigation war chest?” and “Isn’t this just a display of weakness?” are common questions raised by contractors when this issue is discussed. Often, the contractor is well within its contractual or legal rights to withhold money from a breaching subcontractor (another topic for another day). But it may not always be in a contractor’s best interest to withhold every single penny available. This article addresses some of the long-term implications for failing to return withheld sums, including the potential to recover attorneys’ fees, possible bad faith, accruing interest, and overall litigation costs. Admittedly, it can be hard to give money back in the middle of a dispute. But sometimes it can positively impact the overall outcome of the case. Read the court decision
Read the full story...
Reprinted courtesy of William E. Underwood, Jones Walker LLP (ConsensusDocs)
Mr. Underwood may be contacted at wunderwood@joneswalker.com

Congratulations to Haight Attorneys Selected to the 2021 Southern California Super Lawyers List

January 25, 2021 — Haight Brown & Bonesteel LLP
Eight Haight attorneys have been selected to the 2021 Southern California Super Lawyers list. Congratulations to:

Read the court decision
Read the full story...
Reprinted courtesy of Haight Brown & Bonesteel LLP

How the Cumulative Impact Theory has been Defined

November 30, 2020 — David Adelstein - Florida Construction Legal Updates
Largely in the federal contract arena, there is a theory referred to as “cumulative impacts” used by a contractor to recover unforeseeable costs associated with a multitude of changes that have an overwhelming ripple effect on its efficiency, particularly efficiency dealing with its original, base contract work. In other words, by dealing with extensive changes, there is an unforeseeable impact imposed on the contractor relative to its unchanged or base contract work. Under this theory, the contractor oftentimes prices its cumulative impact under a total cost approach with an examination on its cost overrun. However, this is not an easy theory to prevail on because there needs to be a focus on the sheer number of changes, causation supporting the impact, and whether there were concurrent impacts or delays that played a role in the ripple effect. See, e.g., Appeals of J.A. Jones Const. Co., ENGBCA No. 6348, 00-2 BCA P 31000 (July 7, 2000) (“However, in the vast majority of cases such claims are routinely denied because there were an insufficient number of changes, contractor-caused concurrent delays, disruptions and inefficiencies and/or a general absence of evidence of causation and impact.”). To best articulate how the cumulative impact theory has been defined, I want to include language directly from courts and board of contract appeals that have dealt with this theory. This way the contractor knows how to best work with their experts with this definition in mind–and, yes, experts will be needed–to persuasively package and establish causation and damages stemming from the multitude of changes. While many of these definitions are worded differently, you will see they have the same focus dealing with the unforeseeable ripple effect of the extensive changes. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Construction Contracts Need Amending Post COVID-19 Shutdowns

October 19, 2020 — Richard P. Higgins - Construction Executive
No one could have expected the coronavirus pandemic in the beginning of 2020. True, there were rumblings about a sickness in China that was highly contagious and infecting many people. Death tolls began rising as the world watched in disbelieve. After all, this is 2020. This is not supposed to happen. We should have been able to control the spread of the virus, but we could not. COVID-19 quickly spread throughout the world causing havoc and economic despair. While some sectors of the construction industry are not as impacted as others, contractors industry-wide need to consider how COVID-19 will impact their contractual obligations. Depending on what happens and what the government decides to do to stop the spread of the coronavirus, project delays, supply chain distributions, lost productivity and work stoppages may continue for months. All of this will impact the contracts that contractors have with owners. Contractors may not be able to preform according to the terms of the contract through no fault of their own. Owners may no longer qualify for the financing needed to pay for the project. FORCE MAJEURE According to Investopedia, “force majeure refers to a clause that is included in contracts to remove liability for natural and unavoidable catastrophes that interrupt the expected course of events and prevent participants from fulfilling obligations.” Reprinted courtesy of Richard P. Higgins, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Higgins may be contacted at Richard.Higgins@MCC-CPAs.com

California Superior Court Overrules Insurer's Demurrer on COVID-19 Claim

February 15, 2021 — Tred R. Eyerly - Insurance Law Hawaii
A Superior Court in California overruled the insurer's demurrer to the policy holder's complaint seeking business interruption coverage after government shutdown orders were issued because of the coronavirus pandemic. Goodwill Industries of Orange County, California v. Philadelphia Indemnity Ins. Co., Cal. Superior Ct., Civil No. 30-2020-01169032-CU-IC-CXC (Minute Order Jan. 28,, 2021). The minute order is here [Goodwill Decision]. The insurer demurred on the ground that the insured had not alleged sufficient facts to show "direct physical loss" under the business income, extra expenses and civil authority provisions in the policy because coronavirus and COVID-19 did not physically alter the structure. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

You Need to be a Contractor for Workers’ Compensation Immunity to Apply

November 16, 2020 — David Adelstein - Florida Construction Legal Updates
If you are a contractor, you are aware of workers’ compensation immunity when it comes to injuries on the site; and, if not, you should be. It is this workers’ compensation immunity (where workers compensation is the exclusive form of liability for an injured employee) which is why a contractor should generally always want to ensure its subcontractors have workers’ compensation insurance. Workers’ compensation immunity would protect a contractor that is being sued by a subcontractor’s employees that are injured on the job. For more information on workers’ compensation immunity, please check out this article and this article. In this regard, Florida Statute s. 440.10(1)(b) provides:

In case a contractor sublets any part or parts of his or her contract work to a subcontractor or subcontractors, all of the employees of such contractor and subcontractor or subcontractors engaged on such contract work shall be deemed to be employed in one and the same business or establishment, and the contractor shall be liable for, and shall secure, the payment of compensation to all such employees, except to employees of a subcontractor who has secured such payment.

(If the subcontractor does not have workers’ compensation insurance, the contractor is deemed the statutory employer and its workers’ compensation insurance would apply. Otherwise, the subcontractor’s workers compensation insurance would apply.) Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

New York Court Finds No Coverage Owed for Asbestos Losses Because Insured Failed to Prove Material Terms

February 15, 2021 — Gregory S. Capps & Marianne E. Bradley - White and Williams LLP
In the long-tail insurance context, it is not unusual to have issues arise addressing “lost” or “missing” policies. In an opinion issued on January 22, 2021, a New York court ruled that an insurer did not owe coverage to its insured for underlying asbestos claims because the insured had failed to establish the material terms of a “lost” policy under which it sought coverage for the underlying claims. The lawsuit, Cosmopolitan Shipping Company, Inc. v. Continental Insurance Company,[1] arose out of a coverage dispute between Plaintiff Cosmopolitan Shipping Co., Inc. (Cosmopolitan) and its insurance carrier, Continental Insurance Company (CIC), in connection with bodily injury claims arising out of asbestos exposure. The case provides a good analysis of what an insured must do to establish coverage under a “lost” or “missing” policy. During and after World War II, Cosmopolitan chartered and operated a number of shipping vessels on behalf of United Nations Relief and Rehabilitation Administration (UNRRA). In the 1980s, seamen who had worked on board Cosmopolitan’s vessels between 1946 and 1948 filed lawsuits against Cosmopolitan seeking damages for injuries arising out of alleged exposure to asbestos on Cosmopolitan’s vessels. Cosmopolitan sought coverage from CIC for the claims, alleging that CIC had insured Cosmopolitan’s vessels during the relevant time period under a protection and indemnity policy issued to the UNRAA (the P&I Policy). Reprinted courtesy of Gregory S. Capps, White and Williams LLP and Marianne E. Bradley, White and Williams LLP Mr. Capps may be contacted at cappsg@whiteandwilliams.com Ms. Bradley may be contacted at bradleym@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

GRAND RIDGE FLORIDA EXPERT WITNESS ENGINEER DIRECTORY AND CAPABILITIES